Skip to main content
FAR

FAR

FAC Number: 2024-03
Effective Date: 02/23/2024

42.1302 Suspension of work.

42.1302 Suspension of work.

A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.

Far Parts